Project Description

This was a local authority bridge project which came into delay. An analysis of the programme, utilising contemporaneous progress information demonstrated that the majority of the delay to the project was caused by slow piling works. In the end, this allowed the responsibility for delay as between the employer and the contractor to be resolved by adjudication.